Request for quote once-off for building works at oliewenhuis art museum

{"closingDate":"31 July 2026","closingTime":"12h00"}

{"name":"Mr G. Dlamini PERSON scm","email":"[email protected]","phone":null,"department":"of Arts and Culture and","address":"nal Museum, 36 Aliwal Street, Bloemfontein"}

Returnable Documents: 2 Minimum three contactable written reference letters and/or completion certificates on, and the reference letter and/or completion certificate must be signed by the, N/B Please do not attach appointment letters for previous work done, 4 A copy of valid registration with Construction Industry Development Board (CIDB), CIDB grading 2GB or Higher., Letter of good standing from the Compensation Commissioner (COIDA), CV and copies of qualified and experienced Construction manager or project lead to, The bidder must be registered on CSD and CSD supplier report must be attached. 10, 11 SBD 1 - Invitation to submit a Quotation., 12 SBD 2 – Valid original Tax Clearance Certificate or SARS Tax pin, 13 SBD 3.3 - Pricing Schedule (Professional Services), 14 SBD 4 - Declaration of Interest, 15 SBD 6.1 - Preference Points Claim, 16 SBD 8 - Declaration of bidder’s past Supply Chain Management Practices, 17 SBD 9 - Certificate of Independent Bid Determination

All quotes must be submitted at the Tender box, inside a sealed envelope at 36 Aliwal Street, Bloemfontein 9300 on or before the due date and time.

Must be an established construction company registered in South Africa with CIDB grading 2GB or higher. Must have at least 5 years experience in building repairs/refurbishment with verifiable references. Must employ a qualified Construction Manager/Site Agent registered with ECSA/SACPCMP. Joint ventures allowed if all members meet CIDB requirements and lead partner has 2GB or higher grading. Must pass pre-screening of compulsory documents and achieve minimum 70 points in technical assessment.

construction company for Building works

9 or more reference letters with excellent,

good or satisfactory service ratings of 5

buildings works to buildings

7 - 8 reference letters with excellent,

good or satisfactory service ratings 4

• The bidder’s number of years of experience in ratings of buildings works to buildings

construction/building works as per BOQ to 5 - 6 reference letters with excellent,

buildings. (Reference letters supporting the good or satisfactory service ratings 3 30

provision of construction and the applicable ratings of buildings works to buildings

year’s the service was provided) 3 - 4 reference letters with excellent,

good or satisfactory service ratings 2

ratings of buildings works to buildings

1 - 2 reference letters with excellent,

good or satisfactory service ratings 1

ratings of buildings works to buildings

Project management to building works to Besides meeting the “good” rating, the

heritage buildings important issues are approached in an

innovative and efficient way, indicating

that the service provider has outstanding

• Bidder must allocate a site Agent for this knowledge of the deliverables and meets

project the specifications 100%. The proposal

details ways to improve the project

• The proposal should contain a work plan, outcomes and the quality of the outputs.

showing tasks, timelines The proposal has included value added 5 services that is relevant to the project.

• Did the bidder give, submit clear proposed The sequencing and timing of activities

project timelines for this are very well defined, indicating that the

project? tenderer has optimized the use of

resources and the work plan permits

• Does the project plan cater for risk flexibility to accommodate contingencies

management associated with and risks. The bidder should provide 30this project and mitigation strategy? more than one effective option with

methodologies.

• Project management and turn around The approach is tailored to address the

management (Ability to specific project objectives and

• Deliver on Time) requirements. All key activities are

included in the activity schedule. There

are minor inconsistencies between 4

timing, projects deliverables and the

proposed approach. There is a fair

degree of detail that facilitates

understanding of the proposed work plan.

to address the specific project objectives

and requirements. The approach does 3

not adequately deal with the critical

characteristics of the projects. All key

activities are included in the activity

schedule, but are not detailed. There are

minor inconsistencies between timing,

projects deliverables and the proposed

approach.

A company profile, the mission and values of your organization, proven track record 1 and details of experience in repairs and refurbishment of buildings.

refurbishment of buildings in South Africa. At least 3 written reference letters showing

5 years prior experience in providing repairs and refurbishment to buildings.

approach or detailed proposed 1

specifications.

5 years’ experience or more 5

• The Construction Manager/Site Agent number 4 – 4,9 years’ experience 4of years of experience in construction in building

works/civil works to buildings (CV should be 3 – 3,9 years’ experience 3 30attached. The CV should state the institutions

where the service was provided, and the 2 – 2,9 years’ experience 2respective years)

1 – 1,9 years’ experience 1

Masters degree in construction 5 management/civil engineering

Honours degree in construction 4• The highest qualifications of the Construction management/civil engineering

Manager/Site Agent to be assigned to the Bachelor degree in construction 3 10project, (Proof of qualifications should be management/civil engineering

attached) Diploma in construction management/civil 2 engineering

National diploma in construction 1 management/civil engineering

economy. According to the World Bank, about seven million South Africans have some

form of disability, and they are more likely to experience poverty and unemployment

compared to those without disabilities.

to:

• The Building works as per Bill of Quantities (BOQ) provided.

7.1. Bidder must complete pricing in table below inclusive of VAT.

descriptions. It is the intention that the abbreviated

descriptions be fully described when read with the

applicable measuring system and the relevant

preambles and/or specifications. However, should the

full intent and meaning of any description not be clear,

the contractor shall, before submission of his tender,

call for a written directive from the principal agent,

failing which it shall be assumed that the contractor

has allowed in his pricing for materials and workmanship

in terms of international best practice

Payment Terms: payment certificate, there is to be no presumption of

acceptance. Should the principal agent wish to accept

any such prices prior to the issue of the certificate of

final completion, it shall be in writing

F:............................. V:............................

T:............................ Item

20 Clause 20.0 - Adjustment of the contract value and

fi

The contractor shall be required to issue a Certificate of Compliance pertaining to all electrical work upon practical completion. to the satisfaction of the Principal Agent F:....................... V:........................... T:............................ Item SUMMARY OF CATEGORIES Category : Fixed R........................................ Category : Value R........................................ Category : Time R........................................ Carried to Collection R Section No. 1 Preliminaries Bill No. 1 Preliminaries RUBIQUANT QUANTITY SURVEYORS

B-BBEE Minimum Level: 1

B-BBEE Details: SD and CSD supplier report must be attached. 10

11 SBD 1 - Invitation to submit a Quotation.

12 SBD 2 – Valid original Tax Clearance Certificate or SARS Tax pin

13 SBD 3.3 - Pricing Schedule (Professional Services)

14 SBD 4 - Declaration of Interest

15 SBD 6.1 - Preference Points Claim

16 SBD 8 - Declaration of bidder’s past Supply Chain Management Practices

17 SBD 9 - Certificate of Independent Bid Determination

5 Minimum requirements

The following documents are not compulsory and may be attached;

Order Non-Mandatory documents to be submitted in the order as indicated below

Valid B-BBEE Verification Certificate from a Verification Agency accredited by the

South African National Accreditation Systems (SANAS) or a Registered Auditor

approved by the Independent Regulatory Board of Auditors (IRBA) or an Accounting 1 Officer as contemplated in the Close Corporation Act (CCA) confirming micro

enterprise with annual turnover less than R5 million per annum or a valid BBBEE

declaration.

5.1.1 Matters for noting.

o Non-compliance to the above compulsory requirements will lead to a

disqualification of the bidder, except where non-tax compliant with tax matters

which is subject to grace period of at least 7 days that will be provided to a

preferred service provider should that service provider be non-compliant following

bid evaluation.

o Failure by this preferred service provider to rectify its tax matters to a compliant

status within the grace period provided will lead to an automatic disqualification.

o Validity period for bids or formal written quotations submitted shall be valid for a

minimum period of 90 days. The formal written price quotations received from the

service provider/supplier will be regarded as valid for 90 days despite expiry date

In accordance with the Preferential Procurement Regulations of 2022, NM has determined the following specific goals for which preference points will be awarded: Goal 1: Broad-Based Black Economic Empowerment Section 10 of the B-BBEE Act enjoins every public entity to take into account and apply the B-BBEE Codes of Good Practice in determining and implementing a preferential procurement policy. NM will thus award preference points to suppliers based on their B-

The National Museum - a natural history, cultural history and art museum was established in 1877

and is a declared cultural institution, which resorts under the Department of Arts and Culture and

is governed by a council. The mission of the National Museum is to provide heritage resources

and an enjoyable experience to all people through quality research, conservation, education and

exhibitions. More information about the organisation can be found at www.nasmus.co.za

established construction company in South Africa, verification of professional credential will be

verified with CIDB, ECSA. The contract will be for a period as determine in the project plan with

the Architecture or Agent appointed to oversee this project.

3. Scope/Specifications with deliverables of Service(s) required.

3.1 Contract Period

an integral part of this agreement

The JBCC General Preliminaries (May 2018) published

by the Joint Building Contracts Committee for use with

the JBCC Minor Works Agreement (Edition 5.2 - May

2018. shall be deemed to be incorporated in these bills

of quantities, amended as hereinafter described

The General Preambles for Trades 2017 published by

the Association of South African Quantity Surveyors

shall be deemed to be incorporated in these bills of

quantities and no claims arising from brevity of

description of items fully described in the said General

activities if non compliance poses a serious health and

safety risk to workers and / or other people or property

Construction Regulations, 2003 issued under the

Occupational Health and Safety Act, 1993 (Act No )

that he has made provision for the cost of compliance

with the specified health and safety requirements, the

health and safety plan based on the Act, Construction

safety plan is available on request to an employee,

inspector, sub contractor or principal agent all in terms

of Regulation 5

F:....................... V:........................... T:............................ Item

file, which shall include all documentation required in

terms of the health and safety specification, the Act and

the Construction Regulations, is opened and kept on

site and made available to the Principal Agent or

and safety file to the principal agent

F:....................... V:........................... T:............................ Item

construction safety officer in writing to assist in control

of all safety related aspects on the site. Such

appointments are required to ensure that at all times the

requirements of the Act and Construction Regulations

are adhered to. Refer to Regulation 6. All work as

defined in the Construction Regulations shall be carried

out under the supervision of a component person who

has been appointed in writing for that purpose

F:....................... V:........................... T:............................ Item

risk assessment to be performed by a competent person

appointed in writing and the risk assessment shall form

part of the health and safety plan. A copy of the risk

assessment shall be available on site at all times for

inspection. The Contractor shall at all time carry out the

works in manner to avoid the risk of bodily harm to

persons or risk of damage to any property. He shall take

all precautions regarding training of employees in any

hazards and the related work procedures, health and

safety induction training of employees, visitors or any

other persons entering the site and provide personal

protective equipment to all employees and visitors to the

site which are necessary and adequate to eliminate and

conditions which contribute to the risk of injury to

persons or damage to property in terms of Regulation 7

F:....................... V:........................... T:............................ Item

provision, if any, to take the necessary precautions

regarding the significant hazards and risks identified and

assessed by the design consultants

F:....................... V:........................... T:............................ Item

provision, if any, to comply with the requirements of the

Occupational Health and Safety Act (Act No ) and the Construction Regulations issued there

under which have not been specifically elsewhere

provided

F:....................... V:........................... T:............................ Item

78 Compliance

costs in connection therewith. All prices to include,

unless otherwise stated, for all materials, fabrication,

conveyance and delivery, unloading, storing, unpacking,

hoisting, labour, setting, fitting and fixing in position,

cutting and waste (except where to be measured in

accordance with the standard system of measurement),

patterns, models and templates, plant, temporary works,

returning of packaging, duties, taxes (other than Value

Added Tax), imposts, establishment charges,

overheads, profit and all other obligations arising out of

this agreement. Value Added Tax (VAT) is to be

separately stated on the summary page of these bills of

quantities

cause no unacceptable or unreasonable dust, noise,

vibrations, nuisance, inconvenience, annoyance and the

like to the public, others, other properties and traffic in

so far as they exceed the permissible limitations set by

government legislation or by the local authority. Any

delays, stoppages and the like arising from or in order to

comply with the above will not constitute grounds for an

adjustment to the construction period or contract

value whatsoever

F:........................ V:.........................T:......................... Item

60 Clause 11.6 - Environmental disturbance

F:........................ V:.........................T:......................... Item

61 Clause 11.7 - Works cleaning and clearing

F:............................. V:............................

T:............................ Item

62 Clause 11.8 - Vermin

F:............................. V:............................

T:............................ Item

63 Clause 11.9 - Overhand work

F:............................. V:............................

T:............................ Item

64 Clause 11.10 - Tenant installations

F:............................. V:............................

T:............................ Item

65 Clause 11.11 - Advertising

F:............................. V:............................

T:............................ Item

Tenderer's selections

Before submission of his tender the contractor is to

complete the tenderer's selections in the contract data

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

Section b: general preliminaries

Definitions and interpretation (B1)

25 Clause 1.1 - Definitions

F:............................. V:............................

T:............................ Item

26 Clause 1.2 - Interpretation

F:............................. V:............................

T:............................ Item

Documents (B2)

27 Clause 2.1 - Checking of documents

F:............................. V:............................

T:............................ Item

28 Clause 2.2 - Provisional bills of quantities

F:............................. V:............................

T:............................ Item

29 Clause 2.3 - Availability of construction information

F:............................. V:............................

T:............................ Item

30 Clause 2.4 - Ordering of materials and goods

F:............................. V:............................

T:............................ Item

Previous work and adjoining properties (B3)

31 Clause 3.1 - Previous work - dimensional accuracy

F:............................. V:............................

T:............................ Item

32 Clause 3.2 - Previous work - defects

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

33 Clause 3.3 - Inspection of adjoining properties

F:............................. V:............................

T:............................ Item

The site (B4)

34 Clause 4.1 - Handover of site in stages

F:............................. V:............................

T:............................ Item

35 Clause 4.2 - Enclosure of the works Item

F:............................. V:............................

T:............................

36 Clause 4.3 - Geotechnical and other investigations

F:............................. V:............................

T:............................ Item

37 Clause 4.4 - Encroachments

F:............................. V:............................

T:............................ Item

38 Clause 4.5 - Existing premises occupied

F:............................. V:............................

T:............................ Item

39 Clause 4.6 - Services - known

F:............................. V:............................

T:............................ Item

Management of contract (B5)

40 Clause 5.1 - Management of the works

F:............................. V:............................

T:............................ Item

41 Clause 5.2 - Progress meetings

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

42 Clause 5.3 - Technical meetings

F:............................. V:............................

T:............................ Item

Samples, shop drawings and manufacturer's

instructions (B6)

43 Clause 6.1 - Samples of materials

F:............................. V:............................

T:........................... Item

44 Clause 6.2 - Workmanship samples

F:............................. V:............................

T:............................ Item

45 Clause 6.3 - Shop drawings

F:............................. V:............................

T:............................ Item

46 Clause 6.4 - Compliance with manufacturer's

instructions

F:............................. V:............................

T:............................ Item

Deposits and fees (B7)

47 Clause 7.1 - Deposits and fees

F:.......................... V:........................... T:......................... Item

Temporary services (B8)

48 Clause 8.1 - Water

F:............................. V:............................

T:............................ Item

49 Clause 8.2 - Electricity

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

50 Clause 8.3 - Ablution and welfare facilities

F:............................. V:............................

T:............................ Item

51 Clause 8.4 - Communication facilities

F:............................. V:............................

T:............................ Item

Prime cost amounts (B9)

52 Clause 9.1 - Responsibility for prime cost amounts

F:............................. V:............................

T:............................ Item

Attendance on subcontractors (B10)

53 Clause 10.1 - General attendance N/A

54 Clause 10.2 - Special attendance N/A

General (B11)

55 Clause 11.1 - Protection of the works

F:............................. V:............................

T:............................ Item

56 Clause 11.2 - Protection/isolation of existing works and

works occupied in sections

F:............................. V:............................

T:............................ Item

57 Clause 11.3 - Security of the works

F:............................. V:............................

T:............................ Item

58 Clause 11.4 - Notice before covering work

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

59 Clause 11.5 - Disturbance

Disturbance

All work is to be carried out in such a manner as to

cause no unacceptable or unreasonable dust, noise,

vibrations, nuisance, inconvenience, annoyance and the

like to the public, others, other properties and traffic in

so far as they exceed the permissible limitations set by

government legislation or by the local authority. Any

delays, stoppages and the like arising from or in order to

comply with the above will not constitute grounds for an

adjustment to the construction period or contract

value whatsoever

F:........................ V:.........................T:......................... Item

60 Clause 11.6 - Environmental disturbance

F:........................ V:.........................T:......................... Item

61 Clause 11.7 - Works cleaning and clearing

F:............................. V:............................

T:............................ Item

62 Clause 11.8 - Vermin

F:............................. V:............................

T:............................ Item

63 Clause 11.9 - Overhand work

F:............................. V:............................

T:............................ Item

64 Clause 11.10 - Tenant installations

F:............................. V:............................

T:............................ Item

65 Clause 11.11 - Advertising

F:............................. V:............................

T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

Section c: specific preliminaries

66 Warranties for materials and workmanship

Where warranties for materials and/or workmanship are

called for, the contractor shall obtain a written warranty,

addressed to the employer, from the entity supplying

the materials and/or executing the work and shall deliver

same to the principal agent on final completion of the

contract

The warranty shall state that workmanship, materials

and installation are warranted for a specific period from

the date of practical completion and that any defects

that may arise during the specified period shall be made

good at the expense of the entity supplying the materials

and/or doing the work, upon written notice to do so

The warranty will not be enforced if the work is

damaged by defects in the execution of the works, in

which case the responsibility for replacement shall rest

entirely with the contractor

F:............................. V:............................

T:............................ Item

67 Overtime

Should overtime be required to be worked for any

reason whatsoever, the cost of such overtime is to be

borne by the contractor unless the principal agent has

specifically authorised, prior to execution thereof, that

costs for such overtime are to be borne by the

employer

F:........................ V:.........................T:......................... Item

68 Cooperation of the contractor for cost management

It is specifically agreed that the contractor accepts the

obligation of assisting the principal agent in

implementing proper cost management. The contractor

will be advised by the principal agent of all cost

management procedures which will be implemented to

ensure that the contract value does not exceed the

budget

F:........................ V:.........................T:......................... Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

Occupational Health and Safety

69 Occupational Health and Safety Provision

The contractor must take note that compliance with the

Occupational Health and Safety Act, Construction

Regulations Health & Safety specification is

compulsory. In the event of partial or total non-

compliance, the Principal Agent, notwithstanding any

provisions to the contrary, reserves the right to delay

issuing any progress payment certificate until the

Contractor provides satisfactory proof of compliance.

The Contractor shall not be entitled to any

compensation of whatsoever nature, in eluding interest,

due to such delay of payment. Furthermore, the

Principal Agent may stop any work activity or all work

activities if non compliance poses a serious health and

safety risk to workers and / or other people or property

All references hereunder are to Regulations of the

Construction Regulations, 2003 issued under the

Occupational Health and Safety Act, 1993 (Act No )

The Contractor shall, in submitting his bid, demonstrate

that he has made provision for the cost of compliance

with the specified health and safety requirements, the

Act and Construction Regulations

F:....................... V:........................... T:............................ Item

70 Notification of Construction work

The Contractor shall, before commencing work, notify

the Department of Labour of the intended construction

work in terms of Regulation 3. The Contractor shall

submit the notification in writing, on the appropriate

form, prior to commencement of work

F:....................... V:........................... T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

71 Provision of Health and Safety Plan

The contractor shall provide and demonstrate to the

Principal Agent a suitable and sufficiently documented

health and safety plan based on the Act, Construction

Regulations and the health and safety specification,

which shall be applied from the date of commencement

of and for duration of the construction work. The

Contractor shall ensure that a copy of the health and

safety plan is available on request to an employee,

inspector, sub contractor or principal agent all in terms

of Regulation 5

F:....................... V:........................... T:............................ Item

72 Proof of registration with the compensation fund

The Contractor shall provide proof of his registration and

good standing with the Compensation Fund or a

licensed compensation insurer to the commencement of

work

F:....................... V:........................... T:............................ Item

73 Health and Safety file

The Contractor shall ensure that a health and safety

file, which shall include all documentation required in

terms of the health and safety specification, the Act and

the Construction Regulations, is opened and kept on

site and made available to the Principal Agent or

Inspector upon request. Upon completion of the works,

The Contractor shall hand over a consolidated health

and safety file to the principal agent

F:....................... V:........................... T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

74 Assessment of Construction supervisor and

Construction Safety Officer

The Contractor shall appoint a full-time competent

employee in writing as the Construction supervisor, with

the duty of supervising the construction work. The

Contractor shall appoint a full-time or part-time

construction safety officer in writing to assist in control

of all safety related aspects on the site. Such

appointments are required to ensure that at all times the

requirements of the Act and Construction Regulations

are adhered to. Refer to Regulation 6. All work as

defined in the Construction Regulations shall be carried

out under the supervision of a component person who

has been appointed in writing for that purpose

F:....................... V:........................... T:............................ Item

75 Risk assessment and safety policy

Before commencing work the Contractor shall cause a

risk assessment to be performed by a competent person

appointed in writing and the risk assessment shall form

part of the health and safety plan. A copy of the risk

assessment shall be available on site at all times for

inspection. The Contractor shall at all time carry out the

works in manner to avoid the risk of bodily harm to

persons or risk of damage to any property. He shall take

all precautions regarding training of employees in any

hazards and the related work procedures, health and

safety induction training of employees, visitors or any

other persons entering the site and provide personal

protective equipment to all employees and visitors to the

site which are necessary and adequate to eliminate and

conditions which contribute to the risk of injury to

persons or damage to property in terms of Regulation 7

F:....................... V:........................... T:............................ Item

76 Significant Hazards identified and risk assessment

prepared by the design

The Contractor shall allow for additional financial

provision, if any, to take the necessary precautions

regarding the significant hazards and risks identified and

assessed by the design consultants

F:....................... V:........................... T:............................ Item

Carried to Collection R

Section No. 1

Preliminaries

Bill No. 1

Preliminaries

Rubiquant quantity surveyors

Oliewenhuise roof repair and renovations

77 Additional financial provision

The Contractor shall allow for additional financial

provision, if any, to comply with the requirements of the

Occupational Health and Safety Act (Act No ) and the Construction Regulations issued there

under which have not been specifically elsewhere

provided

F:....................... V:........................... T:............................ Item

be used on this project as per item 5 above 9

The bidder must be registered on CSD and CSD supplier report must be attached. 10

11 SBD 1 - Invitation to submit a Quotation.

12 SBD 2 – Valid original Tax Clearance Certificate or SARS Tax pin

13 SBD 3.3 - Pricing Schedule (Professional Services)

14 SBD 4 - Declaration of Interest

15 SBD 6.1 - Preference Points Claim

16 SBD 8 - Declaration of bidder’s past Supply Chain Management Practices

17 SBD 9 - Certificate of Independent Bid Determination

6.1. Pre-screening, i.e. determination of compliance to compulsory

requirements. They will be required to pass pre-screening to be eligible for

further evaluation.

6.2. Technical assessment based on functionality criterion provided. The bidder

must meet a minimum of 70 points to qualify for preferential procurement

evaluation which is the last stage of evaluation.

6.3. Preferential procurement calculation 80/20, whereby 80 is for price and 20

points for specific preferential goals.

and the contractor shall be deemed to have received

such drawings on the date that such drawings have

been dispatched electronically [4.5]

F:............................. V:............................

T:............................ Item

5 Clause 5.0 - Employer's agents

6 Clause 6.0 - Principal Agent

F:............................. V:............................

T:............................ Item

7 Clause 7.0 - Design responsibility

F:............................. V:............................

T:............................ Item

Insurances and securities (A8-A9)

8 Clause 8.0 - Risks, indemnities and insurances

F:............................. V:............................

T:............................ Item

9 Clause 9.0 - Securities

guarantee for payment.

Completion (A15 - A18)

15 Clause 15.0 - Practical completion

F:............................. V:............................

T:............................ Item

16 Clause 16.0 - Defects liability period and final

completion

F:............................. V:............................

T:............................ Item

17 Clause 17.0 - Revision of the date for practical

completion

claims shall be borne by the contractor. This provision

shall not preclude an adjudicator or an arbitrator

appointed in terms of this agreement [22.5 & 6] from

making a determination on costs

F:............................. V:............................

T:............................ Item

Suspension or termination (A21)

21 Clause 21.0 - Suspension or termination

F:............................. V:............................

T:............................ Item

Dispute resolution (A22)

22 Clause 22.0 - Dispute resolution

F:............................. V:............................

T:............................ Item

called for, the contractor shall obtain a written warranty,

addressed to the employer, from the entity supplying

the materials and/or executing the work and shall deliver

same to the principal agent on final completion of the

contract

3.3 Key Performance Requirements

PERSON [email protected]